Terms of Service

By accessing our website, requesting quotes, or engaging our services, you acknowledge that you have read, understood, and agree to be bound by these Terms. If you do not agree to these Terms, you must not use our website or services.

Concrete Contractors of McKinney provides commercial concrete construction services including but not limited to:

• Tilt-wall construction and structural foundations
• Concrete slabs, parking lots, and paving
• Asphalt paving and overlay services
• Concrete repairs and capital improvements
• Site preparation and excavation
• Concrete demolition and selective demo

All services are provided in accordance with applicable building codes, industry standards, and project specifications.

Our proposals are valid for 30 days from issuance and are based on the information provided at the time of quoting. All work requires a signed contract that includes:

• Scope of work and project specifications
• Project schedule and milestones
• Payment terms and conditions
• Change order procedures
• Permits and regulatory requirements
• Insurance and bonding requirements

Project schedules are established based on the information available at contract execution. We will use reasonable efforts to meet agreed-upon timelines, however:

• Weather conditions may affect concrete placement schedules
• Material availability and supplier delays may impact timelines
• Changes in scope will require schedule adjustments
• Permit delays or inspection scheduling may extend completion dates
• Client-directed changes may affect project completion

Any changes to the original scope of work must be documented through a written change order that includes:

• Description of the change and rationale
• Impact on schedule and timeline
• Cost adjustment and payment terms
• Client approval and authorization

Work will not proceed on change order items until the change order is signed and any additional deposits are received.

Client is responsible for obtaining all necessary permits and approvals. We will assist with permit applications as outlined in the contract. Additional costs for permit requirements not included in the original scope will be billed as change orders.

Client warrants that we will have clear access to the site during agreed work hours. Client is responsible for:

• Site security and protection of existing structures
• Utility locates and protection of underground utilities
• Traffic control for public projects
• Environmental compliance and hazardous material removal
• Coordination with other trades and subcontractors

We maintain comprehensive insurance coverage including general liability, workers' compensation, and commercial auto insurance. All field personnel maintain OSHA 10 or 30 certification. We follow strict safety protocols and conduct regular toolbox talks.

Client acknowledges that construction sites involve inherent risks and agrees to maintain appropriate insurance coverage for their property and operations.

Our total liability for any claim arising out of or related to our services shall not exceed the contract amount. We are not liable for:

• Consequential or indirect damages
• Lost profits or business interruption
• Damage to existing structures due to undisclosed conditions
• Delays caused by factors beyond our control
• Acts or omissions of other contractors or subcontractors

Client agrees to indemnify and hold us harmless from claims, damages, or liabilities arising from:

• Client's negligence or breach of contract
• Damage to existing structures due to undisclosed conditions
• Third-party claims related to site conditions
• Client's failure to obtain proper permits or approvals

Either party may terminate the contract with 30 days written notice. Upon termination:

• Client will pay for all work completed and materials ordered
• We will use reasonable efforts to mitigate costs
• Client remains responsible for payment of all outstanding amounts
• Disputes will be resolved through the dispute resolution process

Any disputes arising from these Terms or our services shall be resolved through:

1. Direct negotiation between the parties
2. Mediation through a neutral third party
3. Binding arbitration in Collin County, Texas

Legal action may only be brought in the courts of Collin County, Texas.

These Terms are governed by and construed in accordance with the laws of the State of Texas, without regard to conflict of law principles. Any legal action must be brought in the courts of Collin County, Texas.

These Terms, together with the signed contract and any attachments, constitute the entire agreement between the parties. Any prior understandings or representations are superseded by this agreement.

If any provision of these Terms is held to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.

Our website is provided “as is” without warranties of any kind. We reserve the right to modify or discontinue the website at any time. Information on our website is for general informational purposes and does not constitute professional advice.

We reserve the right to modify these Terms at any time. Material changes will be communicated to clients with active contracts. Continued use of our services constitutes acceptance of the modified terms.

For questions about these Terms of Service, please contact us: